New Distribution Centre located at the Port of Cardiff

A Addendum Notice
by ASSOCIATED BRITISH PORTS

Source: Find a Tender
Type: Contract (Works)
Duration: not specified
Value: ___

Sector: CONSTRUCTION
Published: 09 Dec 2021
Delivery: not specified
Deadline: n/a

Concepts

Location

Geochart for 1 buyers and 0 suppliers

1 buyer

Associated British Ports London

Description

Associated British Ports (ABP) intend to procure a Contractor to deliver the design and construction of a 11,000m2 distribution center comprising warehouse and office accommodation and associated external works (including but not limited to its associated civils, landscaping, car parking, service yard and van storage) on a site covering approximately 24 acres at the Port of Cardiff as further detailed within Appendix 1 of this PQQ document.

Ammendments to Previous Notice

2. Notice

II.2.4) Description of the procurementAssociated British Ports (ABP) intend to procure a Contractor to deliver the designand construction of a 11,000m2 distribution center comprising warehouse and officeaccommodation and associated external works (including but not limited to itsassociated civils, landscaping, car parking, service yard and van storage) on a sitecovering approximately 24 acres at the Port of Cardiff as further detailed withinAppendix 1 of this the PQQ document. The overall estimated duration of the design and constructionof the works, is to be 8 months. The start date is envisaged to be March 2022 whichwould result in completion of the whole of the works by October 2022. Whilst thestart and completion dates may move based on this procurement process, the overalldurations for the design and construction of the works will remain as 8 months. TheContract is 10 months.The Contract will include key dates and sectional completion dates including conditionsto be met for these dates as the Contractor will have to accommodate work (to beclearly defined in the scope and contract data part one) by others not employed byABP. ABP intend to engage with the successful bidder under the NEC 4 ECC OptionA form of contract with amendments which will include provisions for delaydamages. The successful Contractor is required to take on full responsibility for thedesign in its entirety including the design provided by the Client. The Contractor isto complete the design and construct the works. The total estimated contract valueis circa £25 million. works.Organisations wishing to participate must submit a completed PQQ document by the 14th January 2022.

3. Notice

Thu Dec 9 12:00:00 2021 Fri Jan 14 17:00:00 2022

4. Notice

III.1.6) Deposits and guarantees requiredPreviously blank - no entry made requiredThe utility may require a parent company/bank guarantee and/or performance bond (as appropriate) as a condition of any contract to be awarded

5. Notice

Place of performance NUTS CodesUK - United Kingdom L22 Cardiff

6. Notice

III.1.8) Legal form to be taken by the group of economic operators to whom the contract is to be awardedPreviously blank - no entry awardedNo specific legal form is required at this stage. However, the utility reserves the right to require the successful contractor to take a specific legal form and/or assume joint and several liability if bidding on a consortium/subcontracting basis. This will be subject to discussion during the procurement process.

7. Notice

VI.4.1) Review bodyOfficial Name:Associated British PortsPostal Name:High Court of JusticePostal Address: 25 Bedford StreetTown:LondonPostal Code:WC2E 9ESCountry:United KingdomE-mailprocurement@abports.co.uk Royal Courts of Justice, StrandTown:LondonPostal Code:WC2A 2LLCountry:United Kingdom

8. Notice

VI.4.2) Body responsible for mediation procedureOfficial Name:Associated British PortsPostal Address:25 Bedford StreetTown:LondonPostal Code:WC2E 9ESCountryUnited KingdomE-mail:procurement@abports.co.uk procedureBlank - no entry made

9. Notice

II.2.7) Duration of the contract, framework agreement or dynamic purchasing systemDuration in months: 8 10

CPV Codes

45213000 - Construction work for commercial buildings, warehouses and industrial buildings, buildings relating to transport